1、*USACE / NAVFAC / AFCESA / NASA UFGS-01 32 17.00 20 (August 2010)-Preparing Activity: NAVFAC SupersedingUFGS-01 32 17.00 20 (December 2009)UFGS-01 32 17.00 20 (November 2009)UNIFIED FACILITIES GUIDE SPECIFICATIONS*SECTION TABLE OF CONTENTSDIVISION 01 - GENERAL REQUIREMENTSSECTION 01 32 17.00 20NETWO
2、RK ANALYSIS SCHEDULES (NAS)08/10PART 1 GENERAL1.1 DESCRIPTION1.2 SUBMITTALS1.3 SCHEDULE ACCEPTANCE PRIOR TO START OF WORK1.4 SOFTWARE1.5 QUALIFICATIONS1.6 NETWORK SYSTEM FORMAT1.6.1 Diagrams1.6.2 Schedule Activity Properties and Level of Detail1.6.2.1 Activity Categories1.6.2.2 Contract Milestones a
3、nd Constraints1.6.2.3 Activity Code1.6.2.4 Anticipated Weather Delays1.6.2.5 Cost Loading1.6.3 Schedule Software Settings and Restrictions1.6.4 Required Tabular Reports1.7 SUBMISSION AND ACCEPTANCE1.7.1 Monthly Network Analysis Updates1.7.2 As-Built Schedule1.8 CONTRACT MODIFICATION1.9 PROJECT FLOAT
4、1.10 THREE-WEEK LOOK AHEAD SCHEDULEPART 2 PRODUCTSPART 3 EXECUTION- End of Section Table of Contents -SECTION 01 32 17.00 20 Page 1Provided by IHSNot for ResaleNo reproduction or networking permitted without license from IHS-,-,-*USACE / NAVFAC / AFCESA / NASA UFGS-01 32 17.00 20 (August 2010)-Prepa
5、ring Activity: NAVFAC SupersedingUFGS-01 32 17.00 20 (December 2009)UFGS-01 32 17.00 20 (November 2009)UNIFIED FACILITIES GUIDE SPECIFICATIONS*SECTION 01 32 17.00 20NETWORK ANALYSIS SCHEDULES (NAS)08/10*NOTE: This guide specification covers the preparation and use of Design-Bid-Build Network Analysi
6、s Schedule.Insert this guide specification when a fixed-price construction contract is contemplated and the contract amount is expected to exceed $750,000, and the contract duration is expected to exceed 6 months. Insert this guide specification in such contracts when the contract amount is expected
7、 to be less than $750,000 and the contract duration is expected to be less than 6 months, when there is a known critical completion date for the Supported Command. Consult the Administering FEAD/ROICC Office on all construction contracts under the stated threshold values to determine if insertion of
8、 this guide specification is required.Insert this guide specification on all NAVFAC Pacific Marianas, Hawaii and Diego Garcia projects.This section shall be reviewed and approved by the administering FEAD/ROICC prior to completion of the Invitation For Bids (IFB).Coordination is required with Sectio
9、n 01 20 00.00 20, PRICE AND PAYMENT PROCEDURES, when cost loaded Network Analysis Schedules is specified.Comments and suggestions on this specification are welcome and should be directed to the NAVFAC technical proponent of the specification. A listing of Technical Proponents, including their organi
10、zation designation and telephone number, is on the Internet.Recommended changes to a UFGS should be submitted as a Criteria Change Request (CCR).Use of electronic communication is encouraged.SECTION 01 32 17.00 20 Page 2Provided by IHSNot for ResaleNo reproduction or networking permitted without lic
11、ense from IHS-,-,-Brackets are used in the text to indicate designer/FEAD/ROICC choices or locations where text must be supplied by the designer/FEAD/ROICC.*PART 1 GENERAL1.1 DESCRIPTIONThe Contractor is responsible for scheduling procurement, Contractor quality control and construction, acceptance
12、testing and training. Refer to Specification Section 01 33 00 SUBMITTAL PROCEDURES to determine if any items require Government approval prior to construction; If any are required, that submittal review time shall be included in the schedule.The schedule is a tool to manage the project, both for Con
13、tractor and Government activities. It will also be used to report progress and evaluate time extensions. If cost-loaded, it will provide the basis for progress payments.The Contractor shall use the Critical Path Method (CPM) and the Precedence Diagram Method (PDM) to satisfy time and cost applicatio
14、ns. For consistency, when scheduling software terminology is used in this specification, the terms in Primaveras scheduling programs are used.1.2 SUBMITTALS*NOTE: Review Submittal Description (SD) definitions in Section 01 33 00 SUBMITTAL PROCEDURES. Edit the following list to reflect only the submi
15、ttals required for the project. Keep submittals to the minimum required for adequate quality management and Government construction management activities.A “G” following a submittal item indicates that the submittal requires Government approval. Some submittals are already marked with a “G”. Only de
16、lete an existing “G” if the submittal item is not complex and can be reviewed through the Contractors Quality Control system. Only add a “G” if the submittal is sufficiently important or complex in context of the project.*The use of a “G“ following a submittal indicates that a Government approval ac
17、tion is required. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES, except as modified in this contract.SD-01 Preconstruction SubmittalsQualifications; GBaseline Network Analysis Schedule (NAS); GSD-07 CertificatesMonthly Network Analysis Schedule Update; GSECTION 01 32
18、17.00 20 Page 3Provided by IHSNot for ResaleNo reproduction or networking permitted without license from IHS-,-,-SD-11 Closeout SubmittalsAs-Built Schedule; G1.3 SCHEDULE ACCEPTANCE PRIOR TO START OF WORKThe Contracting Officer and Contractor shall participate in a preliminary meeting(s) to discuss
19、the proposed schedule and requirements of this section prior to the Contractor preparing the Project Baseline Schedule.Government review comments on the Contractors schedule(s) shall not relieve the Contractor from compliance with requirements of the Contract Documents.Only bonds shall be paid prior
20、 to acceptance of the Baseline Network Analysis Schedule (NAS).The acceptance of a Baseline NAS is a condition precedent to:1. The Contractor starting work on the demolition or construction stage(s) of the contract.2. Processing Contractors pay request(s) for construction activities/items of work.3.
21、 Review of any schedule updates.Submittal of the Baseline Network Analysis Schedule, and subsequent schedule updates, shall be understood to be the Contractors certification that the submitted schedule meets all of the requirements of the Contract Documents, represents the Contractors plan on how th
22、e work shall be accomplished, and accurately reflects the work that has been accomplished and how it was sequenced (as-built logic).1.4 SOFTWAREProject schedules must be prepared and maintained using Primavera P3, Primavera SureTrak or current mandated scheduling program. Save files in Concentric P3
23、 or current mandated scheduling program file format, compatible with the Governments version of the scheduling program. Importing data into P3/SureTrak/current mandated scheduling program using data conversion techniques or third party software will be cause for rejection of the submitted schedule.1
24、.5 QUALIFICATIONSThe designated Scheduler for the project shall have prepared and maintained at least 3 previous schedules of similar size and complexity of this contract using SureTrak/P3 or current mandated scheduling program. A resume outlining the qualifications of the Scheduler shall be submitt
25、ed for acceptance to the Contracting Officer. Payment will not be processed until an acceptable Scheduler is provided.1.6 NETWORK SYSTEM FORMATThe system shall include time scaled logic diagrams and specified reports.SECTION 01 32 17.00 20 Page 4Provided by IHSNot for ResaleNo reproduction or networ
26、king permitted without license from IHS-,-,-1.6.1 DiagramsProvide Time-scaled Logic Diagram printed in color on ANSI D size sheets. The diagram shall clearly show activities on the critical path. Include the following information for each activity:a. Activity IDb. Activity Descriptionc. Original Dur
27、ation in Work Daysd. Remaining duratione. Percent Completef. Early Start Dateg. Early Finish Dateh. Total Float1.6.2 Schedule Activity Properties and Level of DetailThe NAS shall identify all Government, Construction Quality Management (CQM), Construction activities planned for the project and all o
28、ther activities that could impact project completion if delayed. Separate activities shall be created for each Phase, Area, Floor Level and Location the activity is occurring. Activity categories included in the schedule are specified below.With the exception of the Contract Award and Contract Compl
29、etion Date (CCD) milestone activities, no activity shall be open-ended; each activity shall have predecessor and successor ties. Once an activity exists on the schedule it may not be deleted or renamed to change the scope of the activity and shall not be removed from the schedule logic without appro
30、val from the Contracting Officer. The ID number for a deleted activity shall not be re-used for another activity. No more than 20 percent of the activities shall be critical or near critical. Critical is defined as having zero days of Total Float. “Near Critical“ is defined as having Total Float of
31、1 to 14 days. Contractor activities shall be driven by calendars that reflect Saturdays, Sundays and all Federal Holidays as non-work days.1.6.2.1 Activity Categoriesa. Procurement Activities: Examples of procurement activities include, but are not limited to; Material/equipment submittal preparatio
32、n, submittal and approval of material/equipment; material/equipment fabrication and delivery, and material/equipment on-site. As a minimum, separate procurement activities will be provided for critical items, long lead items, items requiring government approval and material/equipment procurement for
33、 which payment will be requested in advance of installation. The Contractor shall show each delivery with relationship tie to the Construction Activity specifically for the delivery.b. Government Activities: Government and other agency activities that could impact progress shall be clearly identifie
34、d. Government activities include, but are not limited to; Government approved SECTION 01 32 17.00 20 Page 5Provided by IHSNot for ResaleNo reproduction or networking permitted without license from IHS-,-,-submittal reviews, Government conducted inspections/tests, environmental permit approvals by St
35、ate regulators, utility outages, Design Start, Construction Start, (including Design/Construction Start for each Fast-Track Phase, and delivery of Government Furnished Material/Equipment.c. Quality Management (QM) Activities: CQM Activities shall identify the Preparatory Phase and Initial Phase for
36、each Definable Feature of Work identified in the Contractors Quality Control Plan. These activities shall be added to each Three-Week Look Ahead Schedule referenced in the paragraph entitled “THREE-WEEK LOOK AHEAD SCHEDULE“ and will also be included in each monthly update. The Follow-up Phase will b
37、e represented by the Construction Activities in the Baseline Schedule and in the schedule updates.d. Construction Activities: No on-site construction activity shall have a duration in excess of 20 working days. Separate construction activities shall be created for each Phase, Area, Floor Level and L
38、ocation the activity is occurring. Contractor activities will be driven by calendars that reflect Saturdays, Sundays and all Federal Holidays as non-work days, unless otherwise defined in this contract.e. Turnover and Closeout Activities: Include a separate section with all items on the NAVFAC Red Z
39、one Checklist/POAM that are applicable to this project. The checklist will be provided at the Preconstruction Meeting. As a minimum, this will include all testing, specialized inspection activities, Pre-Final inspection, Punch List Completion, Final Inspection and Acceptance. Add a milestone for the
40、 Facility Turnover Planning Meeting at approximately 75 percent construction contract completion or three to six months prior to BOD, whichever is sooner.1.6.2.2 Contract Milestones and Constraintsa. Project Start Date Milestones: The Contractor shall include as the first activity on the schedule a
41、start milestone titled “Contract Award“, which shall have a Mandatory Start constraint equal to the Contract Award Date.b. Projected Completion Milestone: The Contractor shall include an unconstrained finish milestone on the schedule titled “Projected Completion“. Projected Completion is defined as
42、the point in time the Government would consider the project complete and ready for its intended use. This milestone shall have the Contract Completion (CCD) milestone as its only successor.c. Contract Completion Date (CCD) Milestone: The Contractor shall include as the last activity on the schedule
43、a finish milestone titled “Contract Completion (CCD)“, which shall have a Mandatory Finish constraint equal to the current Contract Completion Date. Calculation of schedule updates shall be such that if the finish of the “Projected Completion“ milestone falls after the contract completion date, then
44、 negative float will be calculated on the longest path and if the finish of the “Projected Completion“ milestone falls before the contract completion date, the float calculation shall reflect positive float on the longest path. The only predecessor to the Contract Completion Date Milestone shall be
45、the Projected Completion milestone.SECTION 01 32 17.00 20 Page 6Provided by IHSNot for ResaleNo reproduction or networking permitted without license from IHS-,-,-1.6.2.3 Activity CodeAt a minimum, the Contractor shall establish activity codes identified in this specification and 3 additional activit
46、y codes identified by the Contracting Officer. Once established, activity codes and values cannot be changed without approval by the Contracting Officer.a. Phase: All activities shall be assigned a 4-digit code value based on the contract phase it occurs in.b. Area Code: All activities shall be assi
47、gned an area code value identifying the Area in which the activity occurs. Activities shall not belong to more than one area. Area is defined as a distinct space, function or activity category; such as, separate structure(s), sitework, project summary, construction quality management, material/equipment procu
